FARSmarterBids
Bid Smarter. Far Smarter.

DSCR

DSCR F18S: ORDERING/TIME OF PERFORMANCE (INDEFINITE DELIVERY - TIME-AND-MATERIAL OR LABOR-HOUR CONTRACT

F18S   52.211-9G66   ORDERING/TIME OF PERFORMANCE (INDEFINITE     DSCR (FEB 1996)
AND                  DELIVERY/TIME AND MATERIAL/LABOR HOUR 
F11F53               CONTRACT)
 
    Delivery orders will be issued by the Contracting Officer, Defense Supply 
Center Richmond, Richmond, VA and shall specify a final date for completion of 
performance considering the following availability requirement regarding the 
contractor's personnel: 

    The contractor shall have at least one approved employee available in each 
labor category with a maximum of (5) five calendar days delay in availability 
from the issue date of any delivery order which orders use of that labor category.
 
    The contractor may delay for fourteen (14) calendar days the availability of 
additional employees in any labor category to work on delivery orders or combinations 
of delivery orders requiring use of additional employees in that labor category.  
The final completion date will be as specified in the delivery order unless the 
contractor formally requests an extension of the performance date under the delivery 
order modification procedures specified herein, provides an explanation for the 
extension beyond reasons provided for in this clause, and the request is granted 
in the form of a formal modification to the delivery order.